HomeMy WebLinkAboutStaff Report 3097City of Palo Alto (ID # 3097)
City Council Staff Report
Report Type: Consent Calendar Meeting Date: 2/11/2013
City of Palo Alto Page 1
Summary Title: BAO and Award of Contract for Ventura Community Center
and Park Renovation
Title: Adoption of a Budget Amendment Ordinance in the Amount of $67,000
and Approval of a Contract with Naturescapes in the Amount of $389,525
For The Ventura Community Center and Park Renovation (3990 Ventura
Court) Project PE-10002
From: City Manager
Lead Department: Public Works
Recommendation
Staff recommends that Council:
1.Adopt the attached Budget Amendment Ordinance (BAO) (Attachment A) in
the amount of $67,000 for the Ventura Community Center & Park
Landscape Renovation Project PE-10002.
2. Approve and authorize the City Manager or his designee to execute the
attached contract with Naturescapes, Inc. (Attachment B) in an amount not
to exceed $389,525 for the Ventura Community Center Park Renovation
Capital Improvement Project PE-10002, with partial funding provided by
the Benches, Signage, Fencing, Walkways, and Perimeter Landscaping
Capital Improvement Project PG-06003 ;
3.Authorize the City Manager or his designee to negotiate and execute one or
more change orders to the contract with Naturescapes, Inc. for related,
additional but unforeseen work which may develop during the project, the
City of Palo Alto Page 2
total value of which shall not exceed $38,953.
Background
The Ventura Community Center is a City owned and maintained facility at 3990
Ventura Court. The City leases this building to a non-profit childcare program, the
Palo Alto Community Child Care, Inc. (PACCC). The rear children’s playground,
turf playfield and asphalt play courts are open to both public and PACCC use daily,
and are used by residents of the surrounding neighborhood as their local park.
The playing fields are also used for city-programmed youth sports and camp
activities throughout the year. A small community garden exists along the
western property line adjacent to the play field.
On November 16, 2011, a community meeting was held to review the planned
improvements and renovations. The community meeting presented the scope of
the improvement project with positive feedback from all community members in
attendance. City staff has been working with the Community Services Department
and the PACCC to schedule the work at a time least disruptive to the users of the
playfield and playground.
Discussion
Project Improvements
The following improvments to the Ventura Community Center focus on the rear
playfield, playground, community garden and asphalt play courts that are utilized
by the surrounding community and youth activity leagues as open parkland.
Planned renovations to the park under this project include:
1.New tot-lot play equipment: Existing play equipment is past its projected
20 year life span and needs to be replaced.
2.Renovated children’s playground equipment and swings: Existing play
equipment is past its projected 20 year life span and needs to be replaced.
In order to reduce cost and reuse portions of the existing equipment where
feasible, the support posts will remain in place with new play elements
attached.
City of Palo Alto Page 3
3.Addition of new rubberized surfacing of the children’s playground: To
increase accessibility to the playground equipment and swings to meet ADA
requirements.
4.Repaving of the asphalt play courts: Grind down and replace damage
asphalt surface. Restripe faded basketball court lines.
5.Modifications to the irrigation system & new irrigation controller: Relocate
existing heads to ensure 100% coverage and increase efficiency of the
system. Install new irrigation controller to increase system efficiency.
6.Installing a new irrigation point of connection, meter, backflow and
mainline: Provide a separate irrigation main-line for the rear playfield to
replace substandard and damaged main-line. Provide a new meter and
backflow to monitor playfield water use and separate the irrigation system
water supply from the VCC’s potable water supply.
7.Added site amenities consisting of (2) benches, (1) trash receptacle and (1)
recycle receptacle: Replace existing aged benches at the playground and
add a trash receptacle and recycle receptacle,which the park currently
lacks.
Staff also included bid alternate items to include:
·Installation of a new chain link fence and gate along the boundary of the
play field and the community garden: The current makeshift fence is in
disrepair. A new fence will provide a better boundary/barricade between
playfield and community garden. Cost: $6605.
·Additional 1,350 sq.ft. of rubberized surfacing at the children’s playground:
Expand the proposed rubberized play area to allow greater access to play
equipment and to better meet ADA standards. Cost: $31,577.
·Five (5) new shade trees along the asphalt play courts: Trees will shade the
existing expanse of asphalt paving area to provide a better play
environment and reduce heat impacts to the facility from the paving. Cost:
$7476.
PACCC Lease Maintenance Requirements
The City’s lease agreement with PACCC specifies that PACCC is responsible for
regular maintenance of the community park area of the Ventura Community
City of Palo Alto Page 4
Center. This project is a capital improvement project focusing on increasing and
improving accessibility, usability and sustainable practices. Capital funds for this
project cover the costs of community park area improvements which fall outside
the scope of maintenance required by PACCC in the lease agreement. These
improvements are replacements or renovations that are beyond the standard day
to day maintenance addressed in the lease agreement.Review of the proposed
renovations and coordination with PACCC has been ongoing throughout the
planning phase, and will continue through the construction renovation phase
should Council approve this contract.
Ventura Purchase Agreement Between Palo Alto Unified School District (PAUSD)
and City
The City purchased the Ventura Community Site from PAUSD in 1980 under the
terms of the Ventura Purchase Agreement (“Agreement”). The Agreement allows
PAUSD the right to repurchase the property for educational purposes, and
specifies the methodology for determining the price if PAUSD decides to exercise
this right. The Agreement requires the City to notify PAUSD sixty days in advance
of making any improvements exceeding $100,000, with the $100,000 threshold to
be increased annually in accordance with the applicable Construction Index.
PAUSD is not required to pay the value of any improvements as part of the
repurchase price if notice of intent to repurchase is given by PAUSD before the
end of the sixty day notification by the City that improvements are planned. The
sixty day notification to PAUSD (Attachment C) was given by the City on January
17, 2013.
In an effort to allow the work to begin prior to the March 17, 2013 end of the sixty
day notification period, the PAUSD at the January 29 School Board meeting
waived the 60 day notification and second meeting reading requirement with a 5-
0 vote to allow the project to go forward immediately. Staff has tentatively set
February 18th as the start date for the project.
Bid Process
On November 6, 2012, a notice inviting formal bids (IFB) for the Ventura
Community Center Park Renovation Project was posted at City Hall, and was sent
to 3 builder’s exchanges and 7 contractors. The bidding period was 22 calendar
City of Palo Alto Page 5
days. On November 27, 2012, bids were received from 2 qualified contractors as
listed on the attached Bid Summary (Attachment B).
Summary of Bid Process
Proposed Length of Project 45 calendar days
Number of Bid Packages Sent
to Contractors
7
Number of Bid Packages Sent
to Builder’s Exchanges
1
Total Days to Respond to Bid 22
Pre-Bid Meeting?No
Number of Bids Received:2
Bid Price Range (base bid plus
alternates)
$389,524.65 -$425,470.07
Bids ranged, including the bid alternate items from a high of $425,470.07 to a low
bid of $389,524.65 and ranged from 9% above to 1% below the engineer’s
estimate of $392,792. Staff has reviewed all bids and recommends that the bid
totaling $389,524.65 submitted by Naturescapes be accepted and that
Naturescapes be declared the lowest responsible bidder.
Staff reviewed other similar projects performed by Naturescapes. There were no
significant complaints with their previous work. Staff also checked with the
Contractor's State License Board and found that the contractor has an active
license on file.
Staff recommends the adoption of a Budget Amendment Ordinance (BAO) in the
amount of $67,000 to complete the full scope of work including the bid alternates
in the bid plan package. Staff also recommends awarding the base bid plus bid
alternates for a contract total of $389, 525.
City of Palo Alto Page 6
Resource Impact
Funding for the Ventura Community Center Park Renovation Project is available in
Capital Improvement Program (CIP) Project PE-10002 for $346,928 and from
Benches, Signage, Fencing, Walkways and Perimeter Landscaping CIP PG-06003
for the site furnishings for $17,038. The remaining funds will be added to the
project via the attached BAO funded by the Capital Fund Infrastructure Reserve,
which will decrease to $12,740,013. The additional $67,000 from the BAO will
fund the costs of the base bid, bid alternate items and additional miscellaneous
costs such as printing, testing, and inspection for a total budget of $430,966.
Budget for this project will be as follows;
Available budget (PE-10002)$346,928
Site furnishings (PG-06003)$17,038
BAO $67,000
TOTAL $430,966
Policy Implications
This project is in conformance with City of Palo Alto’s Comprehensive Plan and
does not represent any changes to existing City policies.
Timeline
Following Council approval of the contract, construction is scheduled to begin in
February 2013.
Environmental Review
This project is categorically exempt from the California Environmental Quality Act
(CEQA) under Section 15301c of the CEQA Guidelines as repair, maintenance
and/or minor alteration of the existing facilities and no further environmental
review is necessary.
Attachments:
City of Palo Alto Page 7
·A -Budget Amendment Ordinance (DOC)
·B -Ventura Community Center & Park Contract (PDF)
·C -60 Day Work Notice (PDF)
Attachment A
ORDINANCE NO.xxxx
ORDINANCE OF THE COUNCIL OF THE CITY OF PALO ALTO
AMENDING THE BUDGET FOR THE FISCAL YEAR 2013 TO
PROVIDE AN APPROPRIATION OF $67,000 TO CAPITAL
IMPROVEMENT PROGRAM PROJECT NUMBER PE-10002,
VENTURA COMMUNITY CENTER AND PARK
The Council of the City of Palo Alto does ordain as follows:
SECTION 1. The Council of the City of Palo Alto finds and
determines as follows:
A. Pursuant to the provisions of Section 12 of Article
III of the Charter of the City of Palo Alto, the Council on
June 18, 2012 did adopt a budget for fiscal year 2013; and
B.In fiscal years 2010, 2011, and 2012, the Council
appropriated $360,000 for CIP Project PE-10002, Ventura
Community Center and Park, to renovate the playground, picnic
area, athletic field, and irrigation system at the Ventura
Community Center; and
C. On November 6, 2012, a notice inviting formal bids
for the Ventura Community Center Park Renovation Project was
issued. Bids were received from two qualified contractors,
and Naturescapes was declared the lowest responsible bidder
with a bid of $389,525 plus a 10 percent contingency of
$38,953 for unforeseen work which may develop during the
project. The bid includes costs of $17,038 for site
furnishings which will be covered by CIP Project PG-06003
Benches, Signage, Fencing, Walkways, and Landscaping;and
D. Miscellaneous costs of $2,488 are anticipated for
printing, testing, and inspection; and
E. The current available balance for CIP Project PE-
10002 is $346,928. An additional appropriation of $67,000 is
needed to complete the full scope of the project; and
G. City Council authorization is needed to amend the 2013
budget as hereinafter set forth.
Attachment A
SECTION 2.The sum of Sixty-Seven Thousand Dollars
($67,000) is hereby appropriated to CIP Project PE-10002,
Ventura Community Center and Park.
SECTION 3.Sixty-Seven Thousand Dollars ($67,000) is
hereby transferred from the Capital Fund Infrastructure
Reserve, leaving a balance of $12,740,013.
SECTION 4. As specified in Section 2.28.080(a) of the
Palo Alto Municipal Code, a two-thirds vote of the City
Council is required to adopt this ordinance.
SECTION 5. As provided in Section 2.04.330 of the Palo
Alto Municipal Code, this ordinance shall become effective
upon adoption.
SECTION 6.The resurfacing project is categorically
exempt from the California Environmental Quality Act (CEQA)
under Section 15301c of the CEQA Guidelines as repair,
maintenance and/or minor alteration of the existing facilities
and no further environmental review is necessary.
INTRODUCED AND PASSED:
AYES:
NOES:
ABSTENTIONS:
ABSENT:
ATTEST:APPROVED:
______________________________________________________________
City Clerk Mayor
APPROVED AS TO FORM:________________________________
City Manager
______________________________________________________________
Senior Assistant City Attorney Director of Public Works
____________________________________
Director of Administrative Services
Invitation for Bid (IFB) Package 1 Rev. July 2012
CONSTRUCTION CONTRACT
CONSTRUCTION CONTRACT
Contract No. C13147440
City of Palo Alto
and
Naturescapes, Corp.
PROJECT
Ventura Community Center & Park Project
CIP: PE‐1002
Invitation for Bid (IFB) Package 2 Rev. July 2012
CONSTRUCTION CONTRACT
CONSTRUCTION CONTRACT
TABLE OF CONTENTS
SECTION 1. INCORPORATION OF RECITALS AND DEFINITIONS……………………………….. .................... 5
1.1 Recitals ................................................................................................................ 5
1.2 Definitions ........................................................................................................... 5
SECTION 2. THE PROJECT……………………………………………………………………………… .............................. 5
SECTION 3. THE CONTRACT DOCUMENTS…………………………………………………………. ......................... 5
3.1 List of Documents …………………………………………………………………………………………. ..... 5
3.2 Order of Precedence …………………………………………………………………………… ................ 6
SECTION 4. THE WORK ………………………………………………………………………………… .............................. 7
SECTION 5. PROJECT TEAM ………………………………………………………………………….. ............................. 7
SECTION 6. TIME OF COMPLETION ………………………………………………………………….. .......................... 7
6.1 Time Is of Essence ........................................................................................ ……… 7
6.2 Commencement of Work ..................................................................................... 7
6.3 Contract Time ....................................................................................................... 7
6.4 Liquidated Damages ............................................................................................. 7
6.4.1 Entitlement……………………………………………………………………………………………. 7
6.4.2 Daily Amount…………………………………………………………………………………………. 8
6.4.3 Exclusive Remedy………………………………………………………………………………….. 8
6.4.4 Other Remedies…………………………………………………………………………………... 8
6.5 Adjustments to Contract Time ........................................................................... … 8
SECTION 7. COMPENSATION TO CONTRACTOR………………………………………………………………………... 8
7.1 Contract Sum ……………………………………………………………………………………………………… 1
7.2 Full Compensation …………………………………………………………………………………………….. 9
7.3 Compensation for Extra or Deleted Work …………………………………………………………….9
7.3.1 Self Performed Work………………………………………………………………………………… 9
7.3.2 Subcontractors…………………………………………………………………………………………. 9
SECTION 8. STANDARD OF CARE ................................................................................................... 9
SECTION 9. INDEMNIFICATION ...................................................................................................... 10
9.1 Hold Harmless…………………………………………………………………………………………………….. 10
9.2 Survival………………………………………………………………………………………………………………. 10
SECTION 10. NONDISCRIMINATION .............................................................................................. 10
SECTION 11. INSURANCE AND BONDS .......................................................................................... 10
Invitation for Bid (IFB) Package 3 Rev. July 2012
CONSTRUCTION CONTRACT
SECTION 12. PROHIBITION AGAINST TRANSFERS .......................................................................... 11
SECTION 13. NOTICES .................................................................................................................... 11
13.1 Method of Notice ………………………………………………………………………………………………..11
13.2 Notice Recipients ................................................................................................. 11
13.3 Change of Address ............................................................................................... 12
14.1 Resolution of Contract Disputes ........................................................................... 12
14.2 Resolution of Other Disputes ............................................................................... 12
14.2.1 Non‐Contract Disputes ……………………………………………………………………………….12
14.2.2 Litigation, City Election ……………………………………………………...........................13
14.3 Submission of Contract Dispute …………………………………………………………………………..13
14.3.1 By Contractor …………………………………………………………………………………………. 13
14.3.2 By City ……………………………………………………………………………………………………. 13
14.4 Contract Dispute Resolution Process ............................................................... …… 13
14.4.1 Direct Negotiation………………………………………………………………………… ………….13
14.4.2 Deferral of Contract Disputes ………………………………………………………………… 14
14.4.3 Mediation ………………………………………………………………………………………………….14
14.4.4 Binding Arbitration ……………………………………………………………………………………15
14.5 Non‐Waiver …………………………………………………………………………………………………………16
SECTION 15. DEFAULT ................................................................................................................... 16
15.1 Notice of Default .................................................................................................. 16
15.2 Opportunity to Cure Default ................................................................................ 16
SECTION 16. CITY'S RIGHTS AND REMEDIES .................................................................................. 16
16.1 Remedies Upon Default ....................................................................................... 16
16.1.1 Delete Certain Servic………………………………………………………...........................16
16.1.2 Perform and Withhold ……………………………………………………………………………. 16
16.1.3 Suspend The Construction Contract ………………………………………………………….16
16.1.4 Terminate the Construction Contract for Default ……………………………………..17
16.1.5 Invoke the Performance Bond ………………………………………………………………….17
16.1.6 Additional Provisions ……………………………………………………………………………….17
16.2 Delays by Sureties ................................................................................................ 17
16.3 Damages to City ................................................................................................... 17
16.3.1 For Contractor's Default …………………………………………………………………………..17
16.3.2 Compensation for Losses ………………………………………………………………………….17
16.5 Suspension by City for Convenience ..................................................................... 18
16.6 Termination Without Cause ................................................................................. 18
Invitation for Bid (IFB) Package 4 Rev. July 2012
CONSTRUCTION CONTRACT
16.6.1 Compensation ………………………………………………………………………………………….18
16.6.2 Subcontractors …………………………………………………………………………………………18
16.7 Contractor’s Duties Upon Termination ................................................................. 19
SECTION 17. CONTRACTOR'S RIGHTS AND REMEDIES ................................................................... 19
17.1 Contractor’s Remedies ......................................................................................... 19
17.1.1 For Work Stoppage ………………………………………………………………………………….. 19
17.1.2 For City's Non‐Payment …………………………………………………………………………… 19
17.2 Damages to Contractor ........................................................................................ 19
SECTION 18. ACCOUNTING RECORDS ............................................................................................ 19
18.1 Financial Management and City Access .......................................................... ……. 19
18.2 Compliance with City Requests ........................................................................ …. 20
SECTION 19. INDEPENDENT PARTIES ............................................................................................. 20
SECTION 20. NUISANCE ................................................................................................................. 20
SECTION 21. PERMITS AND LICENSES ............................................................................................ 20
SECTION 22. WAIVER .................................................................................................................... 20
SECTION 23. GOVERNING LAW ..................................................................................................... 20
SECTION 24. COMPLETE AGREEMENT ........................................................................................... 21
SECTION 25. SURVIVAL OF CONTRACT .......................................................................................... 21
SECTION 26. PREVAILING WAGES .................................................................................................. 21
SECTION 27. NON APPROPRIATION .............................................................................................. 21
SECTION 28. GOVERNMENTAL POWERS ........................................................................................ 21
SECTION 29. ATTORNEY FEES ........................................................................................................ 21
SECTION 30. COUNTERPARTS ........................................................................................................ 22
SECTION 31. SEVERABILITY ........................................................................................................... 22
Invitation for Bid (IFB) Package 5 Rev. July 2012
CONSTRUCTION CONTRACT
CONSTRUCTION CONTRACT
THIS CONSTRUCTION CONTRACT entered into on February ___ , 2013 (“Execution Date”) by and between
the CITY OF PALO ALTO, a California chartered municipal corporation ("City"), and NATURESCAPE CORP.
("Contractor"), is made with reference to the following:
R E C I T A L S:
A. City is a municipal corporation duly organized and validly existing under the laws of the State of
California with the power to carry on its business as it is now being conducted under the statutes of the
State of California and the Charter of City.
B. Contractor is a California Corporation duly organized and in good standing in the State of
California, Contractor’s License Number 865407. Contractor represents that it is duly licensed by the State
of California and has the background, knowledge, experience and expertise to perform the obligations set
forth in this Construction Contract.
C. On November6, 2012, City issued an Invitation for Bids (IFB) to contractors for the Ventura
Community Center & Park (“Project”). In response to the IFB, Contractor submitted a bid.
D. City and Contractor desire to enter into this Construction Contract for the Project, and other
services as identified in the Bid Documents for the Project upon the following terms and conditions.
NOW THEREFORE, in consideration of the mutual promises and undertakings hereinafter set forth
and for other good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, it is mutually agreed by and between the undersigned parties as follows:
SECTION 1 INCORPORATION OF RECITALS AND DEFINITIONS.
1.1 Recitals.
All of the recitals are incorporated herein by reference.
1.2 Definitions.
Capitalized terms shall have the meanings set forth in this Construction Contract and/or in the
General Conditions. If there is a conflict between the definitions in this Construction Contract and
in the General Conditions, the definitions in this Construction Contract shall prevail.
SECTION 2 THE PROJECT.
The Project is the construction of the Ventura Community Center & Park ("Project").
SECTION 3 THE CONTRACT DOCUMENTS.
3.1 List of Documents.
The Contract Documents (sometimes collectively referred to as “Agreement” or “Bid Documents”) consist
of the following documents which are on file with the Purchasing Division and are hereby incorporated by
reference.
1) Change Orders
2) Field Change Orders
Invitation for Bid (IFB) Package 6 Rev. July 2012
CONSTRUCTION CONTRACT
3) Contract
4) Project Plans and Drawings
5) Technical Specifications
6) Special Provisions
7) Notice Inviting Bids
8) Instructions to Bidders
9) General Conditions
10) Bidding Addenda
11) Invitation for Bids
12) Contractor's Bid/Non‐Collusion Affidavit
13) Reports listed in the Bidding Documents
14) Public Works Department’s Standard Drawings and Specifications dated 2007 and
updated from time to time
15) Utilities Department’s Water, Gas, Wastewater, Electric Utilities Standards dated 2005
and updated from time to time
16) City of Palo Alto Traffic Control Requirements
17) City of Palo Alto Truck Route Map and Regulations
18) Notice Inviting Pre‐Qualification Statements, Pre‐Qualification Statement, and Pre‐
Qualification Checklist (if applicable)
19) Performance and Payment Bonds
20) Insurance Forms
3.2 Order of Precedence.
For the purposes of construing, interpreting and resolving inconsistencies between and among the
provisions of this Contract, the Contract Documents shall have the order of precedence as set forth in the
preceding section. If a claimed inconsistency cannot be resolved through the order of precedence, the City
shall have the sole power to decide which document or provision shall govern as may be in the best
interests of the City.
Invitation for Bid (IFB) Package 7 Rev. July 2012
CONSTRUCTION CONTRACT
SECTION 4 THE WORK.
The Work includes all labor, materials, equipment, services, permits, fees, licenses and taxes, and all other
things necessary for Contractor to perform its obligations and complete the Project, including, without
limitation, any Changes approved by City, in accordance with the Contract Documents and all Applicable
Code Requirements.
SECTION 5 PROJECT TEAM.
In addition to Contractor, City has retained, or may retain, consultants and contractors to provide
professional and technical consultation for the design and construction of the Project. The Project requires
that Contractor operate efficiently, effectively and cooperatively with City as well as all other members of
the Project Team and other contractors retained by City to construct other portions of the Project.
SECTION 6 TIME OF COMPLETION.
6.1 Time Is of Essence.
Time is of the essence with respect to all time limits set forth in the Contract Documents.
6.2 Commencement of Work.
Contractor shall commence the Work on the date specified in City’s Notice to Proceed.
6.3 Contract Time.
Work hereunder shall begin on the date specified on the City’s Notice to Proceed and shall be
completed
not later than .
within Sixty calendar days (60) after the commencement date specified in City’s
Notice to Proceed.
6.4 Liquidated Damages.
6.4.1 Entitlement.
City and Contractor acknowledge and agree that if Contractor fails to fully and
satisfactorily complete the Work within the Contract Time, City will suffer, as a result of
Contractor’s failure, substantial damages which are both extremely difficult and
impracticable to ascertain. Such damages may include, but are not limited to:
(i) Loss of public confidence in City and its contractors and consultants.
(ii) Loss of public use of public facilities.
(iii) Extended disruption to public.
Invitation for Bid (IFB) Package 8 Rev. July 2012
CONSTRUCTION CONTRACT
6.4.2 Daily Amount.
City and Contractor have reasonably endeavored, but failed, to ascertain the actual
damage that City will incur if Contractor fails to achieve Substantial Completion of the
entire Work within the Contract Time. Therefore, the parties agree that in addition to all
other damages to which City may be entitled other than delay damages, in the event
Contractor shall fail to achieve Substantial Completion of the entire Work within the
Contract Time, Contractor shall pay City as liquidated damages the amount of $500 per
day for each Day occurring after the expiration of the Contract Time until Contractor
achieves Substantial Completion of the entire Work. The liquidated damages amount is
not a penalty but considered to be a reasonable estimate of the amount of damages City
will suffer by delay in completion of the Work.
6.4.3 Exclusive Remedy.
City and Contractor acknowledge and agree that this liquidated damages provision shall
be City’s only remedy for delay damages caused by Contractor’s failure to achieve
Substantial Completion of the entire Work within the Contract Time.
6.4.4 Other Remedies.
City is entitled to any and all available legal and equitable remedies City may have where
City’s Losses are caused by any reason other than Contractor’s failure to achieve
Substantial Completion of the entire Work within the Contract Time.
6.5 Adjustments to Contract Time.
The Contract Time may only be adjusted for time extensions approved by City and agreed to by
Change Order executed by City and Contractor in accordance with the requirements of the
Contract Documents.
SECTION 7 COMPENSATION TO CONTRACTOR.
Invitation for Bid (IFB) Package 1 Rev. July 2012
CONSTRUCTION CONTRACT
7.1 Contract Sum.
Contractor shall be compensated for satisfactory completion of the Work in compliance with the
Contract Documents the Contract Sum of Three Hundred Eighty Nine Thousand Five Hundred
Twenty Five Dollars ($389,525).
[This amount includes the Base Bid and Add Alternates 1‐4.]
/ /
/ /
Invitation for Bid (IFB) Package 9 Rev. July 2012
CONSTRUCTION CONTRACT
7.2 Full Compensation.
The Contract Sum shall be full compensation to Contractor for all Work provided by Contractor
and, except as otherwise expressly permitted by the terms of the Contract Documents, shall cover
all Losses arising out of the nature of the Work or from the acts of the elements or any unforeseen
difficulties or obstructions which may arise or be encountered in performance of the Work until
its Acceptance by City, all risks connected with the Work, and any and all expenses incurred due to
suspension or discontinuance of the Work. The Contract Sum may only be adjusted for Change
Orders issued, executed and satisfactorily performed in accordance with the requirements of the
Contract Documents.
7.3 Compensation for Extra or Deleted Work.
The Contract Sum shall be adjusted (either by addition or credit) for Changes in the Work involving
Extra Work or Deleted Work based on one or more of the following methods to be selected by
City:
1. Unit prices stated in the Contract Documents or agreed upon by City and Contractor,
which unit prices shall be deemed to include Contractor Markup and
Subcontractor/Sub‐subcontractor Markups permitted by this Section.
2. A lump sum agreed upon by City and Contractor, based on the estimated Allowable
Costs and Contractor Markup and Subcontractor Markup computed in accordance
with this Section.
3. Contractor’s Allowable Costs, plus Contractor Markup and Subcontractor Markups
applicable to such Extra Work computed in accordance with this Section.
Contractor Markup and Subcontractor/Sub‐subcontractor Markups set forth herein are the full
amount of compensation to be added for Extra Work or to be subtracted for Deleted Work that is
attributable to overhead (direct and indirect) and profit of Contractor and of its Subcontractors
and Sub‐subcontractors, of every Tier. When using this payment methodology, Contractor
Markup and Subcontractor/Sub‐subcontractor Markups, which shall not be compounded, shall be
computed as follows:
7.3.1 Markup Self‐Performed Work.
10% of the Allowable Costs for that portion of the Extra Work or Deleted Work to be
performed by Contractor with its own forces.
7.3.2 Markup for Work Performed by Subcontractors.
15% of the Allowable Costs for that portion of the Extra Work or Deleted Work to be
performed by a first Tier Subcontractor.
SECTION 8 STANDARD OF CARE.
Contractor agrees that the Work shall be performed by qualified, experienced and well‐supervised
personnel. All services performed in connection with this Construction Contract shall be performed in a
manner consistent with the standard of care under California law applicable to those who specialize in
providing such services for projects of the type, scope and complexity of the Project.
Invitation for Bid (IFB) Package 10 Rev. July 2012
CONSTRUCTION CONTRACT
SECTION 9 INDEMNIFICATION.
9.1 Hold Harmless.
To the fullest extent allowed by law, Contractor will defend, indemnify, and hold harmless City, its
City Council, boards and commissions, officers, agents, employees, representatives and volunteers
(hereinafter collectively referred to as "Indemnitees"), through legal counsel acceptable to City,
from and against any and all Losses arising directly or indirectly from, or in any manner relating to
any of, the following:
(i) Performance or nonperformance of the Work by Contractor or its Subcontractors or Sub‐
subcontractors, of any tier;
(ii) Performance or nonperformance by Contractor or its Subcontractors or Sub‐
subcontractors of any tier, of any of the obligations under the Contract Documents;
(iii) The construction activities of Contractor or its Subcontractors or Sub‐subcontractors, of
any tier, either on the Site or on other properties;
(iv) The payment or nonpayment by Contractor to any of its employees, Subcontractors or
Sub‐subcontractors of any tier, for Work performed on or off the Site for the Project; and
(v) Any personal injury, property damage or economic loss to third persons associated with
the performance or nonperformance by Contractor or its Subcontractors or Sub‐
subcontractors of any tier, of the Work.
However, nothing herein shall obligate Contractor to indemnify any Indemnitee for Losses
resulting from the sole or active negligence or willful misconduct of the Indemnitee. Contractor
shall pay City for any costs City incurs to enforce this provision. Nothing in the Contract
Documents shall be construed to give rise to any implied right of indemnity in favor of Contractor
against City or any other Indemnitee.
9.2 Survival.
The provisions of Section 9 shall survive the termination of this Construction Contract.
SECTION 10 NONDISCRIMINATION.
As set forth in Palo Alto Municipal Code section 2.30.510, Contractor certifies that in the performance of
this Agreement, it shall not discriminate in the employment of any person because of the race, skin color,
gender, age, religion, disability, national origin, ancestry, sexual orientation, housing status, marital status,
familial status, weight or height of such person. Contractor acknowledges that it has read and understands
the provisions of Section 2.30.510 of the Palo Alto Municipal Code relating to Nondiscrimination
Requirements and the penalties for violation thereof, and will comply with all requirements of Section
2.30.510 pertaining to nondiscrimination in employment.
SECTION 11 INSURANCE AND BONDS.
On or before the Execution Date, Contractor shall provide City with evidence that it has obtained insurance
and Performance and Payment Bonds satisfying all requirements in Article 11 of the General Conditions.
Failure to do so shall be deemed a material breach of this Construction Contract.
Invitation for Bid (IFB) Package 11 Rev. July 2012
CONSTRUCTION CONTRACT
SECTION 12 PROHIBITION AGAINST TRANSFERS.
City is entering into this Construction Contract based upon the stated experience and qualifications of the
Contractor and its subcontractors set forth in Contractor’s Bid. Accordingly, Contractor shall not assign,
hypothecate or transfer this Construction Contract or any interest therein directly or indirectly, by
operation of law or otherwise without the prior written consent of City. Any assignment, hypothecation or
transfer without said consent shall be null and void.
The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of
Contractor or of any general partner or joint venturer or syndicate member of Contractor, if the Contractor
is a partnership or joint venture or syndicate or co‐tenancy shall result in changing the control of
Contractor, shall be construed as an assignment of this Construction Contract. Control means more than
fifty percent (50%) of the voting power of the corporation or other entity.
SECTION 13 NOTICES.
13.1 Method of Notice.
All notices, demands, requests or approvals to be given under this Construction Contract shall be given in
writing and shall be deemed served on the earlier of the following:
(i) On the date delivered if delivered personally;
(ii) On the third business day after the deposit thereof in the United States mail, postage prepaid, and
addressed as hereinafter provided;
(iii) On the date sent if sent by facsimile transmission;
(iv) On the date sent if delivered by electronic mail; or
(v) On the date it is accepted or rejected if sent by certified mail.
13.2 Notice Recipients.
All notices, demands or requests (including, without limitation, Claims) from Contractor to City
shall include the Project name and the number of this Construction Contract and shall be
addressed to City at:
To City: City of Palo Alto
City Clerk
250 Hamilton Avenue
P.O. Box 10250
Palo Alto, CA 94303
Copy to: City of Palo Alto
Public Works Administration
250 Hamilton Avenue
Palo Alto, CA 94301
Attn: Peter Jensen
Or
Invitation for Bid (IFB) Package 12 Rev. July 2012
CONSTRUCTION CONTRACT
City of Palo Alto
Utilities Engineering
250 Hamilton Avenue
Palo Alto, CA 94301
Attn:
In addition, copies of all Claims by Contractor under this Construction Contract shall be provided
to the following:
Palo Alto City Attorney’s Office
250 Hamilton Avenue
P.O. Box 10250
Palo Alto, California 94303
All Claims shall be delivered personally or sent by certified mail.
All notices, demands, requests or approvals from City to Contractor shall be addressed to:
Naturescape Corp.
560 Newhall St.
San Jose, Ca 95110
Attn:Denny Stengel
13.3 Change of Address.
In the event of any change of address, the moving party shall notify the other party of the change
of address in writing. Each party may, by written notice only, add, delete or replace any
individuals to whom and addresses to which notice shall be provided.
SECTION 14 DISPUTE RESOLUTION.
14.1 Resolution of Contract Disputes.
Contract Disputes shall be resolved by the parties in accordance with the provisions of this Section
14, in lieu of any and all rights under the law that either party have its rights adjudged by a trial
court or jury. All Contract Disputes shall be subject to the Contract Dispute Resolution Process set
forth in this Section 14, which shall be the exclusive recourse of Contractor and City for such
Contract Disputes.
14.2 Resolution of Other Disputes.
14.2.1 Non‐Contract Disputes.
Contract Disputes shall not include any of the following:
(i) Penalties or forfeitures prescribed by statute or regulation imposed by a
governmental agency;
(ii) Third party tort claims for personal injury, property damage or death relating to
any Work performed by Contractor or its Subcontractors or Sub‐subcontractors
of any tier;
(iii) False claims liability under California Government Code Section 12650, et. seq.;
(iv) Defects in the Work first discovered by City after Final Payment by City to
Contractor;
(v) Stop notices; or
(vi) The right of City to specific performance or injunctive relief to compel
performance of any provision of the Contract Documents.
Invitation for Bid (IFB) Package 13 Rev. July 2012
CONSTRUCTION CONTRACT
14.2.2 Litigation, City Election.
Matters that do not constitute Contract Disputes shall be resolved by way of an action
filed in the Superior Court of the State of California, County of Santa Clara, and shall not
be subject to the Contract Dispute Resolution Process. However, the City reserves the
right, in its sole and absolute discretion, to treat such disputes as Contract Disputes.
Upon written notice by City of its election as provided in the preceding sentence, such
dispute shall be submitted by the parties and finally decided pursuant to the Contract
Dispute Resolution Process in the manner as required for Contract Disputes, including,
without limitation, City’s right under Paragraph 14.4.2 to defer resolution and final
determination until after Final Completion of the Work.
14.3 Submission of Contract Dispute.
14.3.1 By Contractor.
Contractors may commence the Contract Dispute Resolution Process upon City's written
response denying all or part of a Claim pursuant to Paragraph 4.2.9 or 4.2.10 of the
General Conditions. Contractor shall submit a written Statement of Contract Dispute (as
set forth below) to City within seven (7) Days after City rejects all or a portion of
Contractor's Claim. Failure by Contractor to submit its Statement of Contract Dispute in a
timely manner shall result in City’s decision by City on the Claim becoming final and
binding. Contractor’s Statement of Contract Dispute shall be signed under penalty of
perjury and shall state with specificity the events or circumstances giving rise to the
Contract Dispute, the dates of their occurrence and the asserted effect on the Contract
Sum and the Contract Time. The Statement of Contract Dispute shall include adequate
supporting data to substantiate the disputed Claim. Adequate supporting data for a
Contract Dispute relating to an adjustment of the Contract Time shall include both of the
following:
(i) All of the scheduling data required to be submitted by Contractor under the
Contract Documents to obtain extensions of time and adjustments to the
Contract Time and
(ii) A detailed, event‐by‐event description of the impact of each event on
completion of Work. Adequate data to support a Statement of Contract Dispute
involving an adjustment of the Contract Sum must include both of the following:
(a) A detailed cost breakdown and
(b) Supporting cost data in such form and including such information and
other supporting data as required under the Contract Documents for
submission of Change Order Requests and Claims.
14.3.2 By City.
City's right to commence the Contract Dispute Resolution Process shall arise at any time
following City's actual discovery of the circumstances giving rise to the Contract Dispute.
City asserts Contract Disputes in response to a Contract Dispute asserted by Contractor.
A Statement of Contract Dispute submitted by City shall state the events or
circumstances giving rise to the Contract Dispute, the dates of their occurrence and the
damages or other relief claimed by City as a result of such events.
14.4 Contract Dispute Resolution Process.
The parties shall utilize each of the following steps in the Contract Dispute Resolution
Process in the sequence they appear below. Each party shall participate fully and in good
faith in each step in the Contract Dispute Resolution Process, and good faith effort shall
be a condition precedent to the right of each party to proceed to the next step in the
process.
14.4.1 Direct Negotiations.
Designated representatives of City and Contractor shall meet as soon as possible (but not
later than ten (10) Days after receipt of the Statement of Contract Dispute) in a good
Invitation for Bid (IFB) Package 14 Rev. July 2012
CONSTRUCTION CONTRACT
faith effort to negotiate a resolution to the Contract Dispute. Each party shall be
represented in such negotiations by an authorized representative with full knowledge of
the details of the Claims or defenses being asserted by such party in the negotiations,
and with full authority to resolve such Contract Dispute then and there, subject only to
City’s obligation to obtain administrative and/or City Council approval of any agreed
settlement or resolution. If the Contract Dispute involves the assertion of a right or claim
by a Subcontractor or Sub‐subcontractor, of any tier, against Contractor that is in turn
being asserted by Contractor against City (“Pass‐Through Claim”), then the Subcontractor
or Sub‐Subcontractor shall also have a representative attend the negotiations, with the
same authority and knowledge as described above. Upon completion of the meeting, if
the Contract Dispute is not resolved, the parties may either continue the negotiations or
any party may declare negotiations ended. All discussions that occur during such
negotiations and all documents prepared solely for the purpose of such negotiations shall
be confidential and privileged pursuant to California Evidence Code Sections 1119 and
1152.
14.4.2 Deferral of Contract Disputes.
Following the completion of the negotiations required by Paragraph 14.4.1, all
unresolved Contract Disputes shall be deferred pending Final Completion of the Project,
subject to City’s right, in its sole and absolute discretion, to require that the Contract
Dispute Resolution Process proceed prior to Final Completion. All Contract Disputes that
have been deferred until Final Completion shall be consolidated within a reasonable time
after Final Completion and thereafter pursued to resolution pursuant to this Contract
Dispute Resolution Process. The parties can continue informal negotiations of Contract
Disputes; provided, however, that such informal negotiations shall not be alter the
provisions of the Agreement deferring final determination and resolution of unresolved
Contract Disputes until after Final Completion.
14.4.3 Mediation.
If the Contract Dispute remains unresolved after negotiations pursuant to Paragraph
14.4.1, the parties shall submit the Contract Dispute to non‐binding mediation before a
mutually acceptable third party mediator.
.1 Qualifications of Mediator. The parties shall endeavor to select a mediator who
is a retired judge or an attorney with at least five (5) years of experience in
public works construction contract law and in mediating public works
construction disputes. In addition, the mediator shall have at least twenty (20)
hours of formal training in mediation skills.
.2 Submission to Mediation and Selection of Mediator. The party initiating
mediation of a Contract Dispute shall provide written notice to the other party
of its decision to mediate. In the event the parties are unable to agree upon a
mediator within fifteen (15) Days after the receipt of such written notice, then
the parties shall submit the matter to the American Arbitration Association
(AAA) at its San Francisco Regional Office for selection of a mediator in
accordance with the AAA Construction Industry Mediation Rules.
.3 Mediation Process. The location of the mediation shall be at the offices of City.
The costs of mediation shall be shared equally by both parties. The mediator
shall provide an independent assessment on the merits of the Contract Dispute
and recommendations for resolution. All discussions that occur during the
mediation and all documents prepared solely for the purpose of the mediation
shall be confidential and privileged pursuant to California Evidence Code
Sections 1119 and 1152.
Invitation for Bid (IFB) Package 15 Rev. July 2012
CONSTRUCTION CONTRACT
14.4.4 Binding Arbitration.
If the Contract Dispute is not resolved by mediation, then any party may submit the
Contract Dispute for final and binding arbitration pursuant to the provisions of California
Public Contract Code Sections 10240, et seq. The award of the arbitrator therein shall be
final and may be entered as a judgment by any court of competent jurisdiction. Such
arbitration shall be conducted in accordance with the following:
.1 Arbitration Initiation. The arbitration shall be initiated by filing a complaint in
arbitration in accordance with the regulations promulgated pursuant to
California Public Contract Code Section 10240.5.
.2 Qualifications of the Arbitrator. The arbitrator shall be approved by all parties.
The arbitrator shall be a retired judge or an attorney with at least five (5) years
of experience in public works construction contract law and in arbitrating public
works construction disputes. In addition, the arbitrator shall have at least
twenty (20) hours of formal training in arbitration skills. In the event the parties
cannot agree upon an arbitrator, the provisions of California Public Contract
Code Section 10240.3 shall be followed in selecting an arbitrator possessing the
qualifications required herein.
.3 Hearing Days and Location. Arbitration hearings shall be held at the offices of
City and shall, except for good cause shown to and determined by the arbitrator,
be conducted on consecutive business days, without interruption or
continuance.
.4 Hearing Delays. Arbitration hearings shall not be delayed except upon good
cause shown.
.5 Recording Hearings. All hearings to receive evidence shall be recorded by a
certified stenographic reporter, with the costs thereof borne equally by City and
Contractor and allocated by the arbitrator in the final award.
.6 Limitation of Depositions. The parties may conduct discovery in accordance
with the provisions of section 10240.11 of the Public Contract Code; provided,
however, that depositions shall be limited to both of the following:
(i) Ten (10) percipient witnesses for each party and 5 expert witnesses per
party.
Upon a showing of good cause, the arbitrator may increase the number of
permitted depositions. An individual who is both percipient and expert shall, for
purposes of applying the foregoing numerical limitation only, be deemed an
expert. Expert reports shall be exchanged prior to receipt of evidence, in
accordance with the direction of the arbitrator, and expert reports (including
initial and rebuttal reports) not so submitted shall not be admissible as
evidence.
.7 Authority of the Arbitrator. The arbitrator shall have the authority to hear
dispositive motions and issue interim orders and interim or executory awards.
Invitation for Bid (IFB) Package 16 Rev. July 2012
CONSTRUCTION CONTRACT
.8 Waiver of Jury Trial. Contractor and City each voluntarily waives its right to a
jury trial with respect to any Contract Dispute that is subject to binding
arbitration in accordance with the provisions of this Paragraph 14.4.4.
Contractor shall include this provision in its contracts with its Subcontractors
who provide any portion of the Work.
14.5 Non‐Waiver.
Participation in the Contract Dispute Resolution Process shall not waive, release or compromise
any defense of City, including, without limitation, any defense based on the assertion that the
rights or Claims of Contractor that are the basis of a Contract Dispute were previously waived by
Contractor due to Contractor’s failure to comply with the Contract Documents, including, without
limitation, Contractor’s failure to comply with any time periods for providing notice of requests
for adjustments of the Contract Sum or Contract Time or for submission of Claims or supporting
documentation of Claims.
SECTION 15 DEFAULT.
15.1 Notice of Default.
In the event that City determines, in its sole discretion, that Contractor has failed or refused to
perform any of the obligations set forth in the Contract Documents, or is in breach of any
provision of the Contract Documents, City may give written notice of default to Contractor in the
manner specified for the giving of notices in the Construction Contract.
15.2 Opportunity to Cure Default.
Except for emergencies, Contractor shall cure any default in performance of its obligations under
the Contract Documents within two (2) Days (or such shorter time as City may reasonably require)
after receipt of written notice. However, if the breach cannot be reasonably cured within such
time, Contractor will commence to cure the breach within two (2) Days (or such shorter time as
City may reasonably require) and will diligently and continuously prosecute such cure to
completion within a reasonable time, which shall in no event be later than ten (10) Days after
receipt of such written notice.
SECTION 16 CITY'S RIGHTS AND REMEDIES.
16.1 Remedies Upon Default.
If Contractor fails to cure any default of this Construction Contract within the time period set forth
above in Section 15, then City may pursue any remedies available under law or equity, including,
without limitation, the following:
16.1.1 Delete Certain Services.
City may, without terminating the Construction Contract, delete certain portions of the Work,
reserving to itself all rights to Losses related thereto.
16.1.2 Perform and Withhold.
City may, without terminating the Construction Contract, engage others to perform the Work or
portion of the Work that has not been adequately performed by Contractor and withhold the cost
thereof to City from future payments to Contractor, reserving to itself all rights to Losses related
thereto.
16.1.3 Suspend The Construction Contract.
City may, without terminating the Construction Contract and reserving to itself all rights to Losses
related thereto, suspend all or any portion of this Construction Contract for as long a period of
time as City determines, in its sole discretion, appropriate, in which event City shall have no
Invitation for Bid (IFB) Package 17 Rev. July 2012
CONSTRUCTION CONTRACT
obligation to adjust the Contract Sum or Contract Time, and shall have no liability to Contractor
for damages if City directs Contractor to resume Work.
16.1.4 Terminate the Construction Contract for Default.
City shall have the right to terminate this Construction Contract, in whole or in part, upon the
failure of Contractor to promptly cure any default as required by Section 15. City’s election to
terminate the Construction Contract for default shall be communicated by giving Contractor a
written notice of termination in the manner specified for the giving of notices in the Construction
Contract. Any notice of termination given to Contractor by City shall be effective immediately,
unless otherwise provided therein.
16.1.5 Invoke the Performance Bond.
City may, with or without terminating the Construction Contract and reserving to itself all rights to
Losses related thereto, exercise its rights under the Performance Bond.
16.1.6 Additional Provisions.
All of City’s rights and remedies under this Construction Contract are cumulative, and shall be in
addition to those rights and remedies available in law or in equity. Designation in the Contract
Documents of certain breaches as material shall not waive the City’s authority to designate other
breaches as material nor limit City’s right to terminate the Construction Contract, or prevent the
City from terminating the Agreement for breaches that are not material. City’s determination of
whether there has been noncompliance with the Construction Contract so as to warrant exercise
by City of its rights and remedies for default under the Construction Contract, shall be binding on
all parties. No termination or action taken by City after such termination shall prejudice any other
rights or remedies of City provided by law or equity or by the Contract Documents upon such
termination; and City may proceed against Contractor to recover all liquidated damages and
Losses suffered by City.
16.2 Delays by Sureties.
Without limiting to any of City’s other rights or remedies, City has the right to suspend the
performance of the Work by Contractor’s sureties in the event of any of the following:
(i) The sureties’ failure to begin Work within a reasonable time in such manner as to insure
full compliance with the Construction Contract within the Contract Time;
(ii) The sureties’ abandonment of the Work;
(iii) If at any time City is of the opinion the sureties’ Work is unnecessarily or unreasonably
delaying the Work;
(iv) The sureties’ violation of any terms of the Construction Contract;
(v) The sureties’ failure to perform according to the Contract Documents; or
(vi) The sureties’ failure to follow City’s instructions for completion of the Work within the
Contract Time.
16.3 Damages to City.
16.3.1 For Contractor's Default.
City will be entitled to recovery of all Losses under law or equity in the event of
Contractor’s default under the Contract Documents.
16.3.2 Compensation for Losses.
In the event that City's Losses arise from Contractor’s default under the Contract Documents, City
shall be entitled to withhold monies otherwise payable to Contractor until Final Completion of the
Project. If City incurs Losses due to Contractor’s default, then the amount of Losses shall be
deducted from the amounts withheld. Should the amount withheld exceed the amount deducted,
the balance will be paid to Contractor or its designee upon Final Completion of the Project. If the
Losses incurred by City exceed the amount withheld, Contractor shall be liable to City for the
difference and shall promptly remit same to City.
Invitation for Bid (IFB) Package 18 Rev. July 2012
CONSTRUCTION CONTRACT
16.4 Suspension by City for Convenience.
City may, at any time and from time to time, without cause, order Contractor, in writing, to
suspend, delay, or interrupt the Work in whole or in part for such period of time, up to an
aggregate of fifty percent (50%) of the Contract Time. The order shall be specifically identified as
a Suspension Order by City. Upon receipt of a Suspension Order, Contractor shall, at City’s
expense, comply with the order and take all reasonable steps to minimize costs allocable to the
Work covered by the Suspension Order. During the Suspension or extension of the Suspension, if
any, City shall either cancel the Suspension Order or, by Change Order, delete the Work covered
by the Suspension Order. If a Suspension Order is canceled or expires, Contractor shall resume
and continue with the Work. A Change Order will be issued to cover any adjustments of the
Contract Sum or the Contract Time necessarily caused by such suspension. A Suspension Order
shall not be the exclusive method for City to stop the Work.
16.5 Termination Without Cause.
City may, at its sole discretion and without cause, terminate this Construction Contract in part or
in whole by giving thirty (30) Days written notice to Contractor. The compensation allowed under
this Paragraph 16.5 shall be the Contractor’s sole and exclusive compensation for such
termination and Contractor waives any claim for other compensation or Losses, including, but not
limited to, loss of anticipated profits, loss of revenue, lost opportunity, or other consequential,
direct, indirect or incidental damages of any kind resulting from termination without cause.
16.5.1 Compensation.
Following such termination and within forty‐five (45) Days after receipt of a billing from
Contractor seeking payment of sums authorized by this Paragraph 16.5, City shall pay the
following to Contractor as Contractor’s sole compensation for performance of the Work :
.1 For Work Performed. The amount of the Contract Sum allocable to the portion
of the Work properly performed by Contractor as of the date of termination,
less sums previously paid to Contractor.
.2 For Close‐out Costs. Reasonable costs of Contractor and its Subcontractors and
Sub‐subcontractors for:
(i) Demobilizing and
(ii) Administering the close‐out of its participation in the Project (including,
without limitation, all billing and accounting functions, not including
attorney or expert fees) for a period of no longer than thirty (30) Days
after receipt of the notice of termination.
.3 For Fabricated Items. Previously unpaid cost of any items delivered to the
Project Site which were fabricated for subsequent incorporation in the Work.
16.5.2 Subcontractors.
Contractor shall include provisions in all of its subcontracts, purchase orders and other contracts
permitting termination for convenience by Contractor on terms that are consistent with this
Construction Contract and that afford no greater rights of recovery against Contractor than are
afforded to Contractor against City under this Section.
Invitation for Bid (IFB) Package 19 Rev. July 2012
CONSTRUCTION CONTRACT
16.6 Contractor’s Duties Upon Termination.
Upon receipt of a notice of termination for default or for convenience, Contractor shall, unless the
notice directs otherwise, do the following:
(i) Immediately discontinue the Work to the extent specified in the notice;
(ii) Place no further orders or subcontracts for materials, equipment, services or facilities,
except as may be necessary for completion of such portion of the Work that is not
discontinued;
(iii) Provide to City a description, in writing no later than fifteen (15) days after receipt of the
notice of termination, of all subcontracts, purchase orders and contracts that are
outstanding, including, without limitation, the terms of the original price, any changes,
payments, balance owing, the status of the portion of the Work covered and a copy of
the subcontract, purchase order or contract and any written changes, amendments or
modifications thereto, together with such other information as City may determine
necessary in order to decide whether to accept assignment of or request Contractor to
terminate the subcontract, purchase order or contract;
(iv) Promptly assign to City those subcontracts, purchase orders or contracts, or portions
thereof, that City elects to accept by assignment and cancel, on the most favorable terms
reasonably possible, all subcontracts, purchase orders or contracts, or portions thereof,
that City does not elect to accept by assignment; and
(v) Thereafter do only such Work as may be necessary to preserve and protect Work already
in progress and to protect materials, plants, and equipment on the Project Site or in
transit thereto.
SECTION 17 CONTRACTOR'S RIGHTS AND REMEDIES.
17.1 Contractor’s Remedies.
Contractor may terminate this Construction Contract only upon the occurrence of one of the
following:
17.1.1 For Work Stoppage.
The Work is stopped for sixty (60) consecutive Days, through no act or fault of Contractor, any
Subcontractor, or any employee or agent of Contractor or any Subcontractor, due to issuance of
an order of a court or other public authority other than City having jurisdiction or due to an act of
government, such as a declaration of a national emergency making material unavailable. This
provision shall not apply to any work stoppage resulting from the City’s issuance of a suspension
notice issued either for cause or for convenience.
17.1.2 For City's Non‐Payment.
If City does not make pay Contractor undisputed sums within ninety (90) Days after receipt of
notice from Contractor, Contractor may terminate the Construction Contract (30) days following a
second notice to City of Contractor’s intention to terminate the Construction Contract.
17.2 Damages to Contractor.
In the event of termination for cause by Contractor, City shall pay Contractor the sums provided
for in Paragraph 16.5.1 above. Contractor agrees to accept such sums as its sole and exclusive
compensation and agrees to waive any claim for other compensation or Losses, including, but not
limited to, loss of anticipated profits, loss of revenue, lost opportunity, or other consequential,
direct, indirect and incidental damages, of any kind.
SECTION 18 ACCOUNTING RECORDS.
18.1 Financial Management and City Access.
Contractor shall keep full and detailed accounts and exercise such controls as may be necessary
for proper financial management under this Construction Contract in accordance with generally
Invitation for Bid (IFB) Package 20 Rev. July 2012
CONSTRUCTION CONTRACT
accepted accounting principles and practices. City and City's accountants during normal business
hours, may inspect, audit and copy Contractor's records, books, estimates, take‐offs, cost reports,
ledgers, schedules, correspondence, instructions, drawings, receipts, subcontracts, purchase
orders, vouchers, memoranda and other data relating to this Project. Contractor shall retain these
documents for a period of three (3) years after the later of (i) final payment or (ii) final resolution
of all Contract Disputes and other disputes, or (iii) for such longer period as may be required by
law.
18.2 Compliance with City Requests.
Contractor's compliance with any request by City pursuant to this Section 18 shall be a condition
precedent to filing or maintenance of any legal action or proceeding by Contractor against City
and to Contractor's right to receive further payments under the Contract Documents. City many
enforce Contractor’s obligation to provide access to City of its business and other records referred
to in Section 18.1 for inspection or copying by issuance of a writ or a provisional or permanent
mandatory injunction by a court of competent jurisdiction based on affidavits submitted to such
court, without the necessity of oral testimony.
SECTION 19 INDEPENDENT PARTIES.
Each party is acting in its independent capacity and not as agents, employees, partners, or joint ventures’
of the other party. City, its officers or employees shall have no control over the conduct of Contractor or
its respective agents, employees, subconsultants, or subcontractors, except as herein set forth.
SECTION 20 NUISANCE.
Contractor shall not maintain, commit, nor permit the maintenance or commission of any nuisance in
connection in the performance of services under this Construction Contract.
SECTION 21 PERMITS AND LICENSES.
Except as otherwise provided in the Special Provisions and Technical Specifications, The Contractor shall
provide, procure and pay for all licenses, permits, and fees, required by the City or other government
jurisdictions or agencies necessary to carry out and complete the Work. Payment of all costs and expenses
for such licenses, permits, and fees shall be included in one or more Bid items. No other compensation
shall be paid to the Contractor for these items or for delays caused by non‐City inspectors or conditions set
forth in the licenses or permits issued by other agencies.
SECTION 22 WAIVER.
A waiver by either party of any breach of any term, covenant, or condition contained herein shall not be
deemed to be a waiver of any subsequent breach of the same or any other term, covenant, or condition
contained herein, whether of the same or a different character.
SECTION 23 GOVERNING LAW.
This Construction Contract shall be construed in accordance with and governed by the laws of the State of
California.
Invitation for Bid (IFB) Package 21 Rev. July 2012
CONSTRUCTION CONTRACT
SECTION 24 COMPLETE AGREEMENT.
This Agreement represents the entire and integrated agreement between the parties and supersedes all
prior negotiations, representations, and contracts, either written or oral. This Agreement may be amended
only by a written instrument, which is signed by the parties.
SECTION 25 SURVIVAL OF CONTRACT.
The provisions of the Construction Contract which by their nature survive termination of the Construction
Contract or Final Completion, including, without limitation, all warranties, indemnities, payment
obligations, and City’s right to audit Contractor’s books and records, shall remain in full force and effect
after Final Completion or any termination of the Construction Contract.
SECTION 26 PREVAILING WAGES.
This Project is not subject to prevailing wages. The Contractor is not required to pay prevailing wages in
the performance and implementation of the Project, because the City, pursuant to its authority as a
chartered city, has adopted Resolution No. 5981 exempting the City from prevailing wages. The City
invokes the exemption from the state prevailing wage requirement for this Project and declares that the
Project is funded one hundred percent (100%) by the City of Palo Alto.
Or
The Contractor is required to pay general prevailing wages as defined in Subchapter 3, Title 8 of the
California Code of Regulations and Section 16000 et seq. and Section 1773.1 of the California Labor Code.
Pursuant to the provisions of Section 1773 of the Labor Code of the State of California, the City Council has
obtained the general prevailing rate of per diem wages and the general rate for holiday and overtime work
in this locality for each craft, classification, or type of worker needed to execute the contract for this
Project from the Director of the Department of Industrial Relations. Copies of these rates may be obtained
at cost at the Purchasing office of the City of Palo Alto. Contractor shall provide a copy of prevailing wage
rates to any staff or subcontractor hired, and shall pay the adopted prevailing wage rates as a minimum.
Contractor shall comply with the provisions of Sections 1775, 1776, 1777.5, 1810, and 1813 of the Labor
Code.
SECTION 27 NON APPROPRIATION.
This Agreement is subject to the fiscal provisions of the Charter of the City of Palo Alto and the Palo Alto
Municipal Code. This Agreement will terminate without any penalty (a) at the end of any fiscal year in the
event that the City does not appropriate funds for the following fiscal year for this event, or (b) at any time
within a fiscal year in the event that funds are only appropriated for a portion of the fiscal year and funds
for this Construction Contract are no longer available. This section shall take precedence in the event of a
conflict with any other covenant, term, condition, or provision of this Agreement.
SECTION 28 AUTHORITY.
The individuals executing this Agreement represent and warrant that they have the legal capacity and
authority to do so on behalf of their respective legal entities.
SECTION 29 ATTORNEY FEES.
Each Party shall bear its own costs, including attorney’s fees through the completion of mediation. If the
claim or dispute is not resolved through mediation and in any dispute described in Paragraph 14.2,
22
Invitation for Bid (IFB) Package Rev. July 2012
CONSTRUCTION CONTRACT
the prevailing party in any action brought to enforce the provision of this Agreement may recover its
reasonable costs and attorney’s fees expended in connection with that action. The prevailing party shall be
entitled to recover an amount equal to the fair market value of legal services provided by attorneys
employed by it as well as any attorney’s’ fees paid to third parties.
SECTION 30 COUNTERPARTS
This Agreement may be signed in multiple counterparts, which shall, when executed by all the parties,
constitute a single binding agreement.
SECTION 31 SEVERABILITY.
In case a provision of this Construction Contract is held to be invalid, illegal or unenforceable, the validity,
legality and enforceability of the remaining provisions shall not be affected.
IN WITNESS WHEREOF, the parties have caused this Construction Contract to be executed the
date and year first above written.
CITY OF PALO ALTO
____________________________
Purchasing Manager
City Manager
APPROVED AS TO FORM:
___________________________
Senior Asst. City Attorney
APPROVED:
___________________________
Public Works Director
CONTRACTOR
NATURESCAPE CORP.
By:___________________________
Name:_________________________
Title:________________________
January 14, 2013
Robert Golton
Palo Alto Unified School District
25 Churchill Avenue
Palo Alto, CA 94306‐1099
Subject: 60 Day Work Notice required by Ventura Purchase Agreement
Dear Mr. Golton,
In accordance with Section 1.H.5 of the 1980 Purchase Agreement between the City of Palo Alto
and the Palo Alto Unified School District (PAUSD) for the Ventura Community Center facility, a
60 day written notice is required to be submitted to the PAUSD by the City prior to commencing
site improvements exceeding $100,000 in value, with the $100,000 threshold to be adjusted
annually by an applicable Construction Index.
This 60 day notice of work is to notify the PAUSD that improvements to the Ventura Community
Center facility that exceed the adjusted $100,000 threshold are scheduled to begin on March
16, 2013. The improvements to be implemented at the facility include an new dedicated
irrigation main‐line and water meter, renovation to the existing turf play field irrigation system,
new tot‐lot play structure, renovated children’s’ play structure and swing, playground
rubberized surface (ADA upgrades), repaving and restriping of the asphalt play courts, a new 5’
tall chain link fence and central gate at the community garden boundary with the play field, two
(2) new benches, one (1) trash receptacles, one (1) recycle receptacle and seven (7) new trees.
The total value of the contract for the work is $389,525.
The City’s contractor for the project is ready to begin the Ventura improvements prior to March
16 if it is possible for the PAUSD to waive the 60 day written notice requirement in this
instance. I will be contacting you shortly to inquire about that possibility.
Thank you very much for your attention to this matter.
Best Regards,
Brad Eggleston
Assistant Director of Public Works
Engineering Services Division