Loading...
HomeMy WebLinkAbout1997-04-22 City Council (21)City of Palo Alto C ty Manager’s Rep r 2 TO:HONORABLE CITY COUNCIL FROM:CITY MANAGER DEPARTMENT: Community Services AGENDA DATE: April 22, 1997 CMR: 203:97 SUBJECT:Award of Construction Contract to Del Conte’s Landscaping Inc. for Renovation of the Irrigation System at Eleanor Park. REQUEST This is a request.for approval of a contract with Del Conte’s Landscaping Inc. in the amount of $81,175 for renovation of the irrigation system at Eleanor Park. RECOMMENDATIONS Staff recommends that Council: Approve and authorize the Mayor to execute the attached contract with Del Conte’s Landscaping Inc. in the amount of $81,175 for renovation of the irrigation system at Eleanor Park. Authorize the City Manager or her designee, to negotiate and execute one or more change orders to the contract with Del Conte’s Landscaping Inc. for related but unforeseen work that may ¯ develop. The total value of these change orders shall not exceed $8,117. POLICY IMPLICATIONS The renovation of the irrigation system at Eleanor Park is consistent with the Environmental Resources section of the Comprehensive Plan, which calls for maximizing water retention and minimizing the quantity and effects of water runoff. In addition, the award of this contract is consistent with existing policies. EXECUTIVE SUMMARY Pro_iect Description The work to be performed under the contract is for renovation of the present irrigation lines, sprinklers and valves that are worn out, and automation of the existing irrigation system. In addition, the project includes the installation of irrigation satellite controls compatible with the City’s centralized irrigation management system. A replacement backflow device, to protect potable water sources from CMR:203:97 ~Page 1 of 2 contamination, and as mandated by Title 17 of the California Administrative Code, will also be installed as part of this project. Bid Process A competitive bid process was initiated on March 3, 1997. Bids were solicited from ten qualified plumbing/irrigation contractors. A four-week bidding period was allotted, providing contractors with sufficient time to prepare their bids for this project. A mandatory pre-bid meeting was held on March 13, 1997, with four contractors attending (Attachment "A"). Bids were received on April !, 1997 from three qualified bidders, as indicated on the attached bid summary (Attachment°"A"). Contractors who were sent bids, but failed to respond stated that they were either too busy on other projects and/or who were not able to attend the .mandatory pre-bid meeting. Staff has reviewed all bids received and recommends that the bid of $81,175 submitted by Del Conte’s Landscaping Inc., be accepted by Council, and that they be determined to be the lowest responsible bidder. Bids ranged from a high of $143,608 to a low bid of $81,175. This bid, including contingency, is $3,808 or 2.5 percent below staff’s estimate of $93,000. Staff contacted the Contractors’ State License Board and verified that Del Conte’s Landscaping Inc. has an active contractor’s license and that there are no pending disciplinary actions. In addition, staff contacted three of their past clients and found their past performance to be satisfactory. FISCAL IMPACT Funds for this project are available in the Capital ImprovementBudget under CIP #19414, Park Backflow Improvements. ENVIRONMENTAL ASSESSMENT This project is categorically exempt from the provisions of CEQA and no further environmental review is necessary. ATTACHMENTS Attachment "A": Bid Summary Attachment "B": Contract: Del Conte’s Landscape Inc. PREPARED BY: Donald Piana, Superintendent, Parks and Golf Division " Department Head Review: City Manager Approval:~ EM~I H~SON Assistant City Manager CMR:203:97 Page 2 of 2 Attachment A TABULATION OF BID SULTS Project Title: Bid Opening: Renovation of the Irrigation System at Eleanor Park April 1,1997 at 3:00 pm CONTRACTOR PROJECT TOTAL Staff Cost Estimate: $93,000 1. Del Conte Landscaping $81,175 2. J.J. Shooter Inc.$143,608 3. Lone Star Landscape Co.$142,400 4. Jim Lord Landscaping No bid Contractors who did not attend pre-bid meeting: 2. 3. 4. 5. 6. Pacheco Brothers Gardening Gachina Landscape Mngt. B & B Landscaping Shooter and Butts Cagwin/Doward Park City Landscaping Did not attend pre-bid Too busy/other projects Too busy/other projects Too busy/other projects Too busy/other projects Too busy/other projects FORMAL CONTRACT City of Palo Alto PUBLIC WORK CONTRACT No. ~ (Public Work) This Contract, dated , is entered into by and between the City of Palo Alto, a chartered city and a municipal corporation of the State of California ("City") , and.Del Conte’s LandscaDe. Inc., a California CorDoration , ("Contractor"). For and in consideration of the covenants, terms, and conditions ("the provisions") of this Contract, City and Contractor ("the parties") agree: Term. This Contract shall commence and be binding on the parties on the Date of Execution of this Contract, and shall expire on the date of recordation of the Notice of Substantial Completion, or, if no such notice is required to be filed, on the date that final payment is made hereunder, subject to the earlier termination of this Contract. This Contract may be terminated for convenience by the C~ty upon ten (10) days’ prior written notice. General ScoDe of Pro!ect and Work. Contractor shall furnish labor, services, materials and equipment in connection with the construction of the Project and complete the Work in accordance with the covenants, terms and conditions of this Contract to the satisfaction of City. The Project and Work is generally described as follows: Title of Project:ELEANOR PARK IRRIGATION SYSTEM NO.: 95451 Total Bid:$ 81.175.00 Contract Documents. This Contract shall consist of the documents set forth below, which are on file with the City Clerk and are hereby incorporated by reference. For the purposes of construing, interpreting and resolving inconsistencies between and among the provisions of this Contract, these documents and the provisions thereof are set precedence. a. This Contract. b=Invitation For Bid. Specifications and/or Scope of Work. forth in the following descending order of Drawings. Change Orders. Proposal and Bid. Supplementary Conditions. General Conditions. Standard Drawings and Specifications (1992). Certificate of Insurance, Performance Bond, Labor & Materials (Payment) Bond. Affirmative Action Guidelines and Compliance Report. Other Specifications, or part thereof, not expressly incorporated in the Specifications or the Standard Drawings and Specifications (1992). Contract CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev,12/96)SECTION 00500-1 of 8 FORMAL CONTRACT City of Palo Alto m.Any other document not expressly mentioned herein which is issued by City or entered into by the parties¯ o ~. In consideration of Contractor’s performance of its obligations hereunder, City shall pay to Contractor the amount set forth in Contractor’s Bid in accordance with the provisions of this Contract and upon the receipt of written .invoices-and all necessary supporting documentation within the time set forth in the Contract Specifications and the Standard Drawings and Specifications (1992), or, if no time is stated, within thirty (30) Days of the date of receipt of Contractor’s invoices. J~lf~l[]~o On or before the Date of Execution, Contractor shall obtain and maintain the policies of insurance coverage described in the Invitation Forl Bid on terms and conditions and in amounts as may be required by the Risk Manager. City shall not be obligated to take’ out insurance on Contractor’s personal property or the personal property of any person performing labor or services or supplying materials or equipment under the Project. Contractor shall furnish City with the certificates of insurance and with original endorsements affecting coverage required under this Contract on or before the Date of Execution. The certificates and endorsements for each insurance policy shall be signed by a person who is authorized by that insurer to bind coverage in its behalf. Proof of insurance shall be mailed to the Project Manager to the address set forth in Section 15 of this Contract. Indemnification. Contractor agrees to protect, defend, indemnify and hold City, its Council members, officers, employees, agents and representatives harmless from and against any and all claims, demands, liabilities, losses, damages, costs, expenses, liens, penalties, suits, or. judgments, arising, in whole or in Part, directly or indirectly, at any time from any injury to or death of persons or damage to property as a result of the willful acts or the negligent acts or omissions of Contractor, or which results from Contractor’s noncompliance with any Law respecting the condition, use, occupation or safety of the Project site, or any part thereof, or which arises from Contractor’s failure to do anything required under this Contract or for doing anything which Contractor is required not to do under this Contract, or which arises from conduct for which any Law may impose strict liability on Contractor in the performance of or failure to perform the provisions of this Contract, except as may arise from the sole willful acts or negligent acts or omissions of City or any of its Council members, officers, employees, agents or representatives. This indemnification shall extend to any and all claims, demands, or liens made or filed by reason of any work performed by Contractor under this Contract at any time during the term of this Contract, or arising thereafter. To the extent Contractor will use hazardous materials inconnection with the execution of its obligations under this Contract, Contractor further expressly agrees to protect, indemnify, hold harmless and defend City, its City Council members, officers and employees from and against any and all claims, demands, liabilities, losses, damages, costs, expenses, liens, penalties, suits, or judgments City may incur, arising, in whole or in. part, in connection with or as a result of Contractor’s willful acts or negligent acts or omissions under this Contract, under the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. § §9601-6975, as amended.); the Resource Conservation and Recovery Act (42 U.S.C. § §6901-6992k, as amended); the Toxic Substances Control Act (15 U.S.C, § §2601-2692, as amended); the Carpenter-Presley-Tanner Hazardous Substance Account Act (Health & Safety Code, § §25300-25395, as amended); the Hazardous Waste Control Law (Health & Safety Code, § §25100-25250.25, as amended); the Safe Drinking Water and Toxic Enforcement Act (Health & Safety Code, § §25249.5-25249.13, as amended); the Underground Storage of Hazardous Substances Act (Health & Safety Code, § §25280-25299.7, as amended); or under any other local, state or federal law, statute or ordinance, or at common law. " . Contractor agrees to voluntarily assume any and all risk of loss, damage, or injury to the property of Contractor which may occur in, on, or about the Project site at any time and in any manner, CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12/96)SECTION 00500-2 of 8 FORMAL CONTRACT Cit~, of Palo Alto excepting such loss, injury, or damage as may be caused by the sole willful act or negligent act or omission of City or any of its Council members, officers, employees, agents or representatives. ~Y.aJ.y.~. The acceptance of any payment or performance, or any part thereof, shall not operate as a waiver by City of its rights under this Contract. A waiver by City of any breach of any part or provision of this Contract by Contractor shall.not operate as a waiver or continuing waiver of any subsequent breach of the same or any other provision, nor shall any custom or practice which may arise between the parties in the administration of any part or provision of this Contract be construed to waive or to lessen the right of City to insist upon the performance of Contractor in strict compliance with the covenants, terms and conditions of this Contract. 10. Comoliance with Laws. Contractor shall comply with all Laws now in force or.which may hereafter be in force pertaining to the Project and Work and this Contract, with the requirement of any bond or fire underwriters or other similar body now or hereafter constituted, with any discretionary license or permit issued pursuant to any Law of any public agency or official as well as with any provision of all recorded documents affecting the Project site, insofar as any are required by reason of the use or occupancy of the Project site, and with all Laws pertaining to nondiscrimination and affirmative action in employment and hazardous materials. I~.OB~. As a condition precedent to City;s obligation tO pay compensation to Contractor, and on or before the Date of Execution, Contractor shall furnish to the Project Manager the Bonds as required under the Invitation For Bid. 11.Representations and Warranties. In the supply of any materials and equipment and the rendering of labor and services during the course and scope of the Project and Work, Contractor represents and warrants: ao Any materials and equipment which shall be used during the course and scope of the Project and Work shall be vested in Contractor; bo Any materials and equipment which shall be used during the course and scope of the Project and Work shall be merchantable and fit to be used for the particular purpose for which the materials are required; C=Any labor and services rendered and materials and equipment used or employed during the course and scope of the Project and Work shall be free of defects in workmanship for a period of one (1) year after the recordation of the Notice of Substantial Completion, or, if no such notice is required to be filed, on the date that final payment is made hereunder; do Any manufacturer’s warranty obtained by Contractor shall be obtained or shall be deemed obtained b~, Contractor for and in behalf of City. eo Any information submitted by Contractor prior to the award of Contract, or thereafter, upon request, whether or not submitted under a continuing obligation by the terms of the Contract to do so, is true and correct at the time such information is submitted or made available to the City; fo Contractor has not colluded, cdnspired, or agreed, directly or indirectly, with any person in regard to the terms and conditions of Contractor’s Bid, except as may be permitted by the Invitation For Bid; g=Contractor has the power and authority to enter into this Contract with City, that the individual executing this Contract is duly authorized to do so by appropriate resolution, and that this Contract shall be executed~ delivered and performed pursuant to the power and authority conferred upon the CITY of PALO ALTO: ELEANOR PARK RENOVATION (Revo12196)SECTION00500-3 of 8 FORMAL CONTRACT City of Palo Alto person or persons authorized to bind Contractor; Contractor has not made an attempt to exert undue influence with the Purchasing Manager or Project Manager or any other person who has directly contributed to City’s decision to award the contract to Contractor; There are no unresolved claims or disputes between Contractor and City which would materially affect Contractor’s ability to perform under the Contract; Contractor has furnished and will furnish true and accurate statements, records, reports, resolutions, certifications, and other written information as may be requested of Contractor by City from time to time during the term of this Contract; k=Contractor and any person performing labor and services under this Project are duly licensed by the State of California as required by California Business & Professions Code Section 7028, as amended; and ~ Contractor has fully examined and inspected the Project site and has full knowledge 0f the physical conditions of the Project site. 12.Assianment. This Contract and the performance required hereunder is personal to Contractor, and it shall not be assigned by Contractor. Any attempted assignment shall be null and void. 13.Claims of Contracto[. All claims pertaining to extra work, additional charges, or delays within the Contract Time or other disputes arising out of the Contract shall be submitted by Contractor to City in writing by certified or registered mail within ten (10) Days after the claim arose or within such other time asmay be permitted or required by law, and shall be described in sufficient detail to give adequate notice of the substance of the claim to City. 14.~1~. During the term of this Contract and for a period of not less than three (3) years after the expiration or earlier termination of this Contract, City shall have the right to audit Contractor’s Project-related and Work-related writings and business records, as such terms are defined in California Evidence Code Sections 250 and 1271, as amended, during the regular business hours of Contractor, or, if Contractor has no such hours, during the regular business hours of City. 15.1~;;~£,.~. All agreements, appointments, approvals, authorizations, claims, demands, Change Orders, consents, designations, notices, offers, requests and statements given by either party to the other shall be in writing and shall be sufficiently given and served upon the other party if (I) personally served, (2) sent by the United States mail, postage prepaid, (3) sent by private express delivery service, or (4) in the case of a facsimile transmission, if sent to the telephone FAX number set forth below during regular business hours of the receiving party and followed within two (2) Days by-delivery of a hard copy of the material sent by facsimile transmission, in accordance with (1), (2) or (3) above. Personal service shall include, without limitation, service by delivery and service by facsimile transmission. To City: City of Palo Alto ’ City Clerk 250 Hamilton Avenue P.O. Box 10250 Palo Alto, CA 94303 CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12/96)SECTION 00500-4 of 8 FORMAL CONTRACT Copy to: To Contractor: City of Palo Alto Department of Community Services 250 Hamilton Avenue P.O. Box 10250 Palo Alto, CA 94303 (415)-~ FAX: (415)-_~5_~_?._. ATTN: Don Piana, Project Manager DEL CONTE’S LANDSCAPE.. INC. 4300 Bettencourt Way Union citv. Ca 94587 City of Palo Alto 17. (510) 353-6030 FAX: (_.5_J_0__) . 353-6036 ATTN: Rick Le Blanc Aoorooriation of City Funds. This Contract is subject to the fiscal provisions of Article III, Section 12 of the Charter of the City of Palo Alto. Any charges hereunder for labor, services, materials and equipment may accrue only after such expenditures have been approved in advance in writing in accordance with applicable Laws. This Contract shall terminate without penalty |i) at the end of any fiscal year in the event that funds are not appropriated for the following fiscal year, or (ii) at any time within a fiscal year in the event that funds are only appropriated for a portion of the fiscal year and funds for this Contract are no longer available. This Section 16 shall control in the event of a conflict with any other provision of this Contract. Miscellaneous. ao Bailee Disclaimer. The parties understand and agree that City does not purport to be Contractor’s bailee, and C’ity is, therefore, not responsible for any damage to the personal property of Contractor. Consent. Whenever in this Contract the approval or consent, of a party is required, such.approval or consent shall be in writing and shall be executed by a person having the express authority to grant such approval or consent. Controlling Law. The parties agree that this Contract shall be governed and construed by and in accordance with the Laws of the State of California. Definitions. The definitions and terms set forth in Section 1 of the Standard Drawings and Specifications (1992) of this Contract are incorporated herein by reference. Force Majeure. Neither party shall be deemed to be in default on ~ccount of any delay or failure to perform its obligations under this Contract which directly results from an Act of God or an act of a superior governmental authority. CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12196)SECTION 00500-5 of 8 FORMAL CONTRACT City of Palo Alto Headings. The paragraph headings are not a part of this Contract and shall have no effect upon the construction or interpretation of any part of this Contract. Incorporation of Documents. All documents constituting the Contract documents described in Section 3 hereof and all documents which may, from time to time, be referred to in any duly executed amendment hereto are by such reference incorporated in this Contract and shall be deemed to be part of this Contract. Integration. This Contract and any amendments hereto between the parties constitute the entire agreement between the parties concerning the Project and Work, and there are no other prior oral or written agreements between the parties that are not incorporated in this Contract. Modification of Agreement. This Contract shall not be modified or be binding upon the parties, unless such modification is agreed to in writing and signed by the parties. Provision. Any agreement, covenant, condition, clause, qualification, restriction, reservation, term or other stipulation in the Contract shall define or otherwise control, establish, or limit the performance required or permitted or to be required of or permitted by either party. All provisions, whether covenants or conditions, shall be deemed to be both covenants and conditions. EQ Resolution. Contractor shall submit with its Bid a copy of any corporate or partnership resolution or other writing, which authorizes any director, officer or other employee or partner to act for or in behalf of Contractor or which authorizes Contractor to enter into this Contract. ng Severability. If a court of competent jurisdiction finds or rules that any provision of this Contract is void or unenforceable, the provisions of this Contract not so affected shall remain in full force and effect. Status of Contractor. In the exercise of rights and obligations under this Contract~ Contractor acts as an independent contractor and not as an agent or employee of City. Contractor shall not be entitled to any rights and benefits accorded or accruing to the City Council members, officers or employees of City, and Contractor expressly waives any and all claims to such rights and benefits. Successors and Assigns. The provisions of this Contract shall inure to the.benefit of, and shall apply to and bind, the successors and assigns of the parties. Time of the Essence. Time is of the essence of this Contract and each of its provisions. In the calculation of time hereunder, the time in which an act is to be performed shall be computed by excluding the first Day and including the last. If the time in which an act is to be performed falls on a Saturday, Sunday, or any Day observed as legal holiday by City, the time for performance shall be extended to the following Business Day. ~ Venue. In the event that Suit is brought by either party hereunder, the parties agree that trial of such action shall be vested exclusively in the state courts of California in the County of Santa Clara in the City of San Jose or in the United States District Court for the Northern District of California in the City of San Jose. qo Recovery of costs. The prevailing party in any action brought to enforce the terms of this Contract or arising out of this Contract may recover its reasonable costs, including reasonable attorney’s fees, CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12/96)SECTION 00500-6 of 8 FORMAL CONTRACT Cit~ incurred or expended in connection with such action against the non-prevailing party. IN WITNESS WHEREOF, the parties have by their duly appointed representatives executed this Contract in the city of,Palo Alto, County of Santa Clara, State of California on the date first stated above. ATTEST:CITY OF PALO ALTO: By: City Clerk Its: Mayor APPROVED: City Manager Director of Public Works DEL CONTE’S LANDSCAPE. INC.CONTRACTOR: By: Name: ~’-~’~ Titlei Director of Administrati,ve Services Taxpayer I.D. No. 94-3154581 Manager Contract Administation (for: Risk) APPROVED AS TO FORM: Senior Asst. City Attorney CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12196)SECTION 00500-7 of 8 FORMAL CONTRACT City of Palo Alto CERTIFICATE OF ACKNOWLEDGMENT (Civil Code § 1189) STATE OF COUNTY OF On , before me, a notary public in and for said County, personally appeared personally known to me (or proved to me on the basis of.satisfactory evidence) to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by ~ his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal. Signature (Seal) END OF SECTION CITY of PALO ALTO: ELEANOR PARK RENOVATION (Rev.12196)SECTION 00500-8 of 8